Welcome to SKR Groups. These Terms and Conditions govern your use of our website and services. By accessing our website or engaging our services, you agree to comply with and be bound by these Terms and Conditions.
If you do not agree with any part of these terms, you must not use our website or services.
2. Company Services
SKR Groups provides services including but not limited to:
-
Architectural design and planning
-
House map design and 3D modeling
-
Construction and project management
-
Renovation and remodeling
-
Building maintenance
-
Engineering consultation and supervision
All services are subject to individual project agreements, quotations, and contracts signed between SKR Groups and the client.
3. Use of Website
By using our website, you agree:
-
To use the website for lawful purposes only
-
Not to misuse, hack, or attempt unauthorized access to the website
-
Not to copy, reproduce, or distribute content without written permission
-
Not to submit false or misleading information through contact forms
We reserve the right to restrict or terminate access to users who violate these terms.
4. Intellectual Property Rights
All content on this website, including:
-
Text
-
Images
-
Designs
-
Logos
-
Project photos
-
Graphics
-
Layout and structure
is the property of SKR Groups unless otherwise stated.
No material may be copied, modified, reproduced, or distributed without prior written consent from SKR Groups.
5. Project Agreements and Payments
All construction and design projects are governed by separate written agreements.
-
Project scope, timeline, and cost will be clearly defined in the contract.
-
Payments must be made as per the agreed payment schedule.
-
Delays in payment may result in suspension of work.
-
Any additional work beyond the agreed scope will require written approval and may incur additional charges.
6. Project Timelines
Project timelines provided are estimates based on available information at the time of agreement. Delays may occur due to:
-
Weather conditions
-
Government approvals
-
Material shortages
-
Client-requested modifications
-
Unforeseen site conditions
SKR Groups shall not be held liable for delays caused by factors beyond reasonable control.
7. Client Responsibilities
Clients agree to:
-
Provide accurate project requirements and information
-
Obtain necessary legal permissions, if required (unless agreed otherwise in writing)
-
Make timely payments
-
Approve designs, drawings, and materials within reasonable time
Failure to comply may result in project delays or additional costs.
8. Limitation of Liability
SKR Groups shall not be liable for:
-
Indirect or consequential damages
-
Loss of profits or business interruption
-
Damages arising from misuse of provided designs or materials
-
Issues resulting from third-party contractors not appointed by SKR Groups
Our liability shall be limited to the amount paid for the specific service under contract.
9. Third-Party Services
Our website may contain links to third-party websites or services. We do not control and are not responsible for:
-
Content
-
Policies
-
Security practices
-
Accuracy of third-party websites
Use of such websites is at your own risk.
10. Warranties and Quality Assurance
We strive to maintain high standards of construction quality and supervision. However:
-
All warranties will be provided as per the specific project contract.
-
Normal wear and tear or damage caused by misuse is not covered.
-
Structural warranties, if applicable, will be clearly mentioned in the project agreement.
11. Confidentiality
All project-related documents, drawings, and business information shared between SKR Groups and clients shall remain confidential unless disclosure is required by law.
12. Termination of Services
We reserve the right to terminate a contract or suspend services if:
-
The client breaches the agreement
-
Payments are not made as agreed
-
The client engages in unlawful activity
-
Safety conditions at the project site are compromised
Termination conditions will follow the signed project contract.
13. Changes to Terms and Conditions
SKR Groups reserves the right to update or modify these Terms and Conditions at any time. Updated versions will be posted on this website.
Continued use of the website or services after changes constitutes acceptance of the revised terms.
14. Governing Law
These Terms and Conditions shall be governed and interpreted in accordance with the laws of Nepal.
Any disputes arising shall be subject to the jurisdiction of the courts of Nepal.
15. Contact Information
For any questions regarding these Terms and Conditions, please contact:
SKR Groups
Sanepa-3, Lalitpur, Nepal
Phone: 01-5912075
Email: skrgroup2075@gmail.com